Welcome to THE TOPO'S GARAGE LLC. By accessing our website or engaging our construction services, you agree to be bound by these Terms and Conditions. Please read them carefully.
1. Acceptance of Terms
By using this website or contracting with THE TOPO'S GARAGE LLC for construction services, you acknowledge that you have read, understood, and agree to be bound by these Terms and Conditions and our Privacy Policy.
2. Services
THE TOPO'S GARAGE LLC provides professional construction services including but not limited to:
- Commercial construction and renovation
- Residential construction and remodeling
- Design-build services
- Structural repairs and improvements
- Project consultation and management
All services are subject to a separate written contract that will outline specific project scope, timeline, pricing, and terms.
3. Quotes and Estimates
Project quotes and estimates provided by THE TOPO'S GARAGE LLC are based on the information available at the time and are valid for 30 days unless otherwise specified. Final project costs may vary based on site conditions, material availability, and scope changes.
4. Contracts and Agreements
All construction projects require a written contract signed by both parties. The contract will supersede any prior oral or written communications and will include:
- Detailed scope of work
- Project timeline and milestones
- Payment terms and schedule
- Change order procedures
- Warranty information
5. Payment Terms
Payment terms will be specified in your project contract. Typically, construction projects require:
- An initial deposit to secure scheduling
- Progress payments tied to project milestones
- Final payment upon project completion and approval
Late payments may be subject to interest charges as permitted by law.
6. SMS Terms & Conditions
If you consent to receive SMS text messages from THE TOPO'S GARAGE LLC, the following terms apply:
Consent to Text Messages
By providing your mobile phone number and checking the consent box on our contact form, you agree to receive text messages from THE TOPO'S GARAGE LLC related to your construction project, quotes, appointments, and service updates. Consent is NOT a condition of purchase.
Message Frequency and Costs
- Message frequency may vary based on your project needs and communication preferences
- Message and data rates may apply as determined by your mobile carrier
- You are responsible for any charges your carrier may apply to text messages
Automated Messaging
We may use an automatic telephone dialing system (ATDS) to send text messages to your mobile number for project updates, reminders, and important notifications.
Opt-Out and Help
- To Opt Out: Reply STOP to any text message to unsubscribe from further messages
- For Help: Reply HELP to any message or contact us at nestor@the-topos-garage.com
Supported Carriers
Our SMS service is compatible with most major U.S. mobile carriers. Message delivery may vary by carrier and location.
7. Project Changes and Delays
Changes to the project scope must be documented through a written change order signed by both parties. Changes may affect the project timeline and cost. We are not liable for delays caused by:
- Weather conditions
- Material shortages or supply chain disruptions
- Permit delays or inspections
- Client-requested changes
- Unforeseen site conditions
8. Permits and Compliance
THE TOPO'S GARAGE LLC will obtain necessary permits for construction work as specified in the project contract. All work will be performed in compliance with applicable building codes and regulations. The client is responsible for providing access to the property and ensuring compliance with any HOA or community requirements.
9. Warranties
We stand behind the quality of our work. Warranty terms for construction projects will be specified in your project contract and typically include:
- Workmanship warranty (typically 1-2 years)
- Material warranties as provided by manufacturers
- Specific exclusions and limitations
Warranties do not cover damage resulting from improper use, neglect, or normal wear and tear.
10. Limitation of Liability
THE TOPO'S GARAGE LLC's liability is limited to the amount paid for the specific services provided. We are not liable for indirect, incidental, or consequential damages arising from our services.
11. Insurance
THE TOPO'S GARAGE LLC maintains general liability insurance and workers' compensation insurance as required by law. Proof of insurance can be provided upon request.
12. Intellectual Property
All design work, plans, and materials created by THE TOPO'S GARAGE LLC remain our intellectual property unless otherwise specified in a written agreement.
13. Termination
Either party may terminate a construction contract under the terms specified in the written agreement. Termination may result in charges for work completed and materials ordered.
14. Dispute Resolution
Any disputes arising from our services will first be addressed through good-faith negotiation. If unresolved, disputes may be submitted to mediation or arbitration as specified in the project contract.
15. Governing Law
These Terms and Conditions are governed by the laws of the State of Florida. Any legal action must be brought in the appropriate courts of Miami-Dade County, Florida.
16. Changes to Terms
We reserve the right to modify these Terms and Conditions at any time. Updated terms will be posted on our website with a new "Last Updated" date. Your continued use of our services constitutes acceptance of any changes.
17. Contact Information
For questions about these Terms and Conditions, please contact:
THE TOPO'S GARAGE LLC
8849W 35 Th Ln
Hialeah, FL 33018
Email: nestor@the-topos-garage.com